Welcome to Riyawa Contractors. By accessing or using our IT and contract services, you agree to be bound by the following terms and conditions. Please read them carefully.
- All IT and contract services provided by Riyawa Contractors are subject to written agreements outlining project scope, timelines, and payment terms.
- Any modifications to agreed-upon services must be documented and signed by both parties.
- We reserve the right to refuse or discontinue services if contractual obligations are not met.
- Payment must be made as per the agreed contract terms before project commencement or milestones.
- Late payments may result in service delays or suspension.
- Deposits made for IT development, consulting, or contractual services are non-refundable unless explicitly stated.
- Clients must provide accurate information and cooperate throughout the service period.
- Any delays due to client inaction may impact project timelines without liability on our part.
- Sensitive data shared with us will be handled with confidentiality, but we are not liable for breaches due to third-party actions.
- Refunds are only applicable if requested within 7 days of payment and if no substantial work has been delivered.
- IT solutions, software, or consulting services that have been commenced or delivered are non-refundable.
- Cancellation of ongoing contracts must follow the termination clauses in the signed agreement.
- We do not guarantee specific results for IT solutions, as performance depends on multiple external factors.
- Riyawa Contractors is not liable for any indirect damages or losses incurred due to service implementation.
- Clients are responsible for ensuring compliance with relevant legal and industry regulations.
- Any disputes arising from service agreements will first be resolved through negotiation.
- If unresolved, mediation or arbitration may be pursued as outlined in the contract.
If you have any questions regarding these terms, feel free to reach out: